Terms & Conditions

Welcome to our website. These Terms & Conditions govern your access to and use of our services related to architecture, interior design, structural engineering, project management and construction. By accessing or using our website and services, you agree to comply with and be bound by these terms. If you do not agree, please do not use our website or services.

1. Definitions

• “Company” / “We” / “Us” / “Our” refers to the service provider.
• “Client” / “You” / “User” refers to any individual or entity using our services.
• “Services” refers to all design, consultancy, execution and related offerings.

2. Scope of Services

We provide professional services including but not limited to:

• Architectural design and planning
• Interior design and execution
• Structural and civil engineering
• MEP coordination and consulting
• Project management and turnkey construction

The scope of each project will be clearly defined in a separate agreement, proposal or contract.

3. Use of Website

• The content on this website is for general information and business purposes only.
• You agree not to misuse the website or attempt unauthorized access.
• You shall not copy, reproduce or distribute any content without prior written consent.

4. Intellectual Property Rights

All content on this website, including designs, drawings, graphics, text, logos and visual elements, are the intellectual property of the company unless stated otherwise.

• Unauthorized use, reproduction or distribution is strictly prohibited.
• Project designs and drawings shared with clients remain protected under applicable intellectual property laws unless explicitly transferred through agreement.

5. Project Engagement & Deliverables

• All services will be executed as per mutually agreed timelines and deliverables.
• Design concepts, drawings and documentation are provided for approved use only.
• Any modifications beyond the agreed scope may incur additional charges and revised timelines.

6. Payments & Commercial Terms

• Payment terms will be defined in the project proposal or agreement.
• Delayed payments may result in project delays or suspension of services.
• All fees paid are non-refundable unless otherwise specified in writing.

7. Client Responsibilities

The client agrees to:

• Provide accurate project information and requirements
• Approve drawings and decisions within reasonable timelines
• Ensure site readiness for execution phases
• Coordinate with external agencies if required

Delays caused by the client may affect project timelines and costs.

8. Third-Party Services

We may collaborate with contractors, vendors, consultants or suppliers for project execution.

• We are not liable for delays or issues caused by third-party services beyond our control.
• Quality and performance will be monitored, but final execution responsibility may depend on involved vendors.

9. Limitation of Liability

• We shall not be liable for any indirect, incidental or consequential damages arising from the use of our services.
• Our liability is limited to the value of services agreed upon in the contract.
• We are not responsible for unforeseen site conditions, regulatory changes or force majeure events.

10. Project Delays & Force Majeure

We shall not be held responsible for delays caused due to:

• Natural disasters, weather conditions or unforeseen events
• Government regulations or approvals
• Material shortages or labor issues
• Client-side delays or changes

11. Termination of Services

We reserve the right to terminate or suspend services if:

• There is a breach of agreement or non-payment
• Misuse of provided designs or documents occurs
• The project becomes unviable due to external conditions

Clients may also terminate services as per agreed contractual terms.

12. Confidentiality

We respect the confidentiality of all client information, project details and business data.

• Sensitive information will not be disclosed without consent unless required by law.
• Clients are also expected to maintain confidentiality of proprietary designs and documents.

13. Revisions & Changes

• Limited revisions may be included as per the project agreement.
• Additional revisions, scope changes or redesigns may be chargeable.
• All changes must be approved in writing to avoid disputes.

14. Governing Law

These Terms & Conditions shall be governed by and interpreted in accordance with the laws of India. Any disputes shall be subject to the jurisdiction of the courts in the relevant project or business location.

15. Changes to Terms

We reserve the right to update or modify these Terms & Conditions at any time without prior notice. Continued use of the website or services constitutes acceptance of the updated terms.

16. Contact Information

For any questions or concerns regarding these Terms & Conditions, please contact us:

Email: thedetails.2013@gmail.com Phone: +91-9407335803
Address: Ground Floor, JCCC College, Shastri Bridge, Napier Town, Jabalpur (M.P.) , 482001

17. Acceptance of Terms

By using our website and engaging with our services, you acknowledge that you have read, understood and agreed to these Terms & Conditions.